Terms of Service

1. Acceptance of Terms

By accessing and using the Denton Concrete Contractors website and services, you accept and agree to be bound by these Terms of Service. If you do not agree to these terms, please do not use our website or services.

2. Services Description

Denton Concrete Contractors provides commercial concrete construction services including, but not limited to:

• Tilt-wall construction
• Commercial foundations
• Parking lot concrete
• Industrial flatwork
• Concrete paving
• Concrete repairs and restoration

All services are provided subject to separate written contracts that outline specific terms, conditions, pricing, and timelines for each project.

3. Quotes and Estimates

Quotes and estimates provided through our website or by our representatives are preliminary and subject to change based on site conditions, project scope, and other factors. Final pricing will be provided in a written contract. Quotes are typically valid for 30 days from the date provided unless otherwise stated.

4. Project Contracts

All commercial concrete projects require a written contract that will include:

• Detailed scope of work
• Project timeline and milestones
• Payment terms and schedule
• Material specifications
• Warranty information
• Insurance and licensing details

No work will commence until a signed contract and any required deposits are received.

5. Payment Terms

Payment terms will be specified in individual project contracts. Typically, commercial projects require a deposit upon contract signing, progress payments during construction, and final payment upon project completion. Late payments may incur additional fees as specified in the contract.

6. Project Changes and Delays

Changes to project scope, specifications, or timeline must be agreed upon in writing and may result in adjustments to pricing and completion dates. We are not responsible for delays caused by:

• Adverse weather conditions
• Client-requested changes or delays
• Unavailability of materials due to supply chain issues
• Site conditions that differ from those represented
• Acts of God or force majeure events

7. Warranties and Guarantees

We warrant that all work will be performed in a professional and workmanlike manner consistent with industry standards. Specific warranty terms, including duration and coverage, will be detailed in individual project contracts. Warranties do not cover damage resulting from improper use, neglect, or normal wear and tear.

8. Limitation of Liability

To the maximum extent permitted by law, Denton Concrete Contractors shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising from or related to our services. Our total liability shall not exceed the total amount paid for the specific service giving rise to the claim.

9. Insurance and Licensing

Denton Concrete Contractors maintains all required licenses, bonds, and insurance coverage including general liability and workers' compensation insurance. Proof of insurance can be provided upon request.

10. Website Use

When using our website, you agree to:

• Provide accurate and current information in all forms
• Not use the website for any unlawful purpose
• Not attempt to gain unauthorized access to any part of the website
• Not transmit any viruses, malware, or harmful code
• Respect all intellectual property rights

11. Intellectual Property

All content on this website, including text, graphics, logos, images, and software, is the property of Denton Concrete Contractors or its content suppliers and is protected by intellectual property laws. You may not reproduce, distribute, or create derivative works from this content without express written permission.

12. Dispute Resolution

Any disputes arising from these Terms of Service or our services will be resolved through good faith negotiation. If negotiation fails, disputes will be resolved through binding arbitration in Denton County, Texas, in accordance with the rules of the American Arbitration Association.

13. Governing Law

These Terms of Service are governed by and construed in accordance with the laws of the State of Texas, without regard to its conflict of law provisions.

14. Changes to Terms

We reserve the right to modify these Terms of Service at any time. Changes will be effective immediately upon posting to this page. Your continued use of our website and services after changes are posted constitutes acceptance of the modified terms.

15. Contact Information

For questions about these Terms of Service, please contact us: